1. Business and services
Nexora Technology provides digital services including websites, AI/business automation, e-commerce, SEO, brand/product design, digital growth management, mobile applications and custom software/SaaS. The exact deliverables are defined in the accepted quotation, proposal, statement of work or written project confirmation.
2. Website pricing and quotations
Prices shown on the website are market-adjusted regional starting estimates unless explicitly stated otherwise. They may vary by selected country to reflect the intended market context and do not replace a final approved quotation. Final pricing may reflect scope, timeline, integrations, third-party costs, taxes and payment structure.
3. Payments and deposits
Payments may be collected through an approved third-party gateway or another agreed business payment method. Any deposit, milestone schedule, recurring amount, due date and transaction currency must be shown in the final quotation or invoice before a live payment is requested.
4. Client responsibilities
Clients are responsible for providing accurate requirements, lawful content, approvals, credentials, timely feedback and any third-party access required to perform the agreed work. Delays or missing dependencies may affect delivery dates.
5. Changes, revisions and additional work
Revision limits and acceptance criteria should be defined in the approved scope. Requests outside that scope may require a change request, revised timeline or additional fee before the work proceeds.
6. Intellectual property and third-party materials
Ownership or licensing of final deliverables follows the project agreement and any payment conditions stated there. Third-party software, fonts, stock assets, APIs, plugins, open-source components and platform services remain subject to their own licences and terms.
7. Client content and lawful use
Clients must have the right to use content, data and materials supplied for the project. Services may not be used for unlawful, deceptive, infringing, abusive or prohibited activity, and a project may be declined or suspended where legal, security or payment concerns reasonably require it.
8. Third-party platforms
Hosting companies, app stores, payment providers, APIs, advertising networks and other external platforms control their own pricing, policies, uptime and approval processes. NEXORA TECHNOLOGY cannot guarantee actions controlled solely by those third parties.
9. Liability and warranties
Any warranties, service levels and limits of liability should be stated in the project agreement and finalized according to the legal business entity and governing law. The website should not promise outcomes that depend on third-party platforms, market behavior or client-controlled systems.
10. Suspension and termination
Work may be paused for overdue payments, material client delays, unlawful requests, security concerns or breach of the agreed terms. Any consequences for completed work, access or outstanding fees should follow the project agreement and refund/cancellation policy.
11. Governing law and disputes
These terms are governed by the applicable laws of the United States and the state in which Nexora Technology is legally established. The parties should first attempt good-faith resolution through the official support channel at support@nexoratechnology.store. Where a dispute cannot be resolved informally, the courts with proper jurisdiction in the United States will have jurisdiction, subject to any mandatory consumer rights that apply.
12. Contact
Official notices and support requests should be sent to support@nexoratechnology.store or the business contact details published on the Contact & Support page.